Agenda of Regional Council Meeting - Wednesday, 26 January 2022

HAWKE’S BAY REGIONAL COUNCIL

Wednesday 26 January 2022

Subject: Significant Organisational Activities Looking Forward through February 2022

Reason for Report

1. The commentary following is for Councillors information, to highlight significant areas of Council activity. Significant Council resources are being directed toward various initiatives, which reflect the Council’s evolving agenda and it is considered important that the Councillors are consistently informed of progress in areas that have or may create a high external profile.

Northern Catchment
Project / Activity Description	Significant Upcoming Milestone(s)	Group /Team or Section
Wairoa River Parade Erosion Protection	1. Physical works for the sheet piled wall have been completed. Reinstatement of guard railing and concept planting plans will be completed next month.	Regional Projects
Biodiversity and biosecurity	2. Work will begin at the Mahia scenic reserve to remove the remaining possums after the contractor control was completed. This will be a significant area of focus for the team over the next two months. 3. Wireless monitored leg hold traps will begin to be placed out after battery replacements for units have been completed. This trap layout will be the final one in preparation for the Proof of Absence monitoring required to show that possum eradication has been successful. 4. The pest plant team will be following up on privet tree enquiries received in January and organizing contractors for landowners who have received doctors certificates. Work will also be underway on Old Mans Beard particularly north of SH5. 5. The animal team are planning work for the increased PCA (possum control) monitoring package for 2022-2023. 6. Rabbit management plans are being prepared for Opouahi Station and Rangiora Trust. 7. Education monitoring will be occurring through the following PCA’s during February - Taihape Rd, Flag Range, Matapiro and Crownthorpe PCA’s. 8. Contractors are detoxifying all bait stations set up through Department of Conservation (DOC) areas within HBRC’s river berm contract as required by the associated DOC permission.	ICM – Catchment Services
Whakakī Freshwater Improvement Fund Project	9. Easement documents have now been signed by the Whakakī Lake Trust for the weir. Community hui will be scheduled for February to discuss the project and the timing of the works. 10. Final stages of the former Whakakī school renovations targeting electrical, plumbing and painting will be completed in February/March.	ICM – Catchment Delivery
East Coast farmers Expo	11. Planning has begun for a display at the East Coast farmers Expo to be held on 23-24 February 2022.	ICM – Catchment Delivery
Nuhaka Slip	12. Negotiations are underway with landowners, including multiple ownership properties, to achieve agreement on treatment types and cooperation. Good progress is being made, however, it is expected that agreement with some of the multiple ownership blocks will take time to conclude.	ICM – Catchment Delivery

Central Catchments
Project / Activity Description	Significant Upcoming Milestone(s)	Group /Team or Section
Omaranui Landfill expansion resource consent applications	13. Consent application Hearing held 1 and 2 November 2021. Hearing was adjourned until 30 March 2022 to allow planning witnesses to meet with the objective of reaching consensus on an agreed set of conditions.	Policy & Regulation Consents
Flood Control Schemes - Resilience Funded projects	14. Taradale stopbank strengthening physical works underway, 200m of strengthening works have been completed to date. 15. Moteo and East Clive stopbank design options are being finalised. 16. Roys Hill and Ngatarawa stopbank design options are being finalised.	Asset Management Engineering Regional Projects
Gravel Management	17. Hearing took place on 10 December 2021, but no decision was made. The consent conditions will be reviewed, and a meeting with submitters to agree on all conditions will be scheduled for February 2022.	Asset Management Consents, Schemes
Waitangi Regional Park	18. Planning and design for Stage III development of the Park, including safe vehicle access to the river and two ephemeral wetlands on the flat berm area is near completion for delivery in the fourth quarter of the financial year. Funding application to Department of Internal Affairs (DIA) fund for a new toilet block in the park will be undertaken in February 2022 and submitted in March by the Atea a Rangi Educational Trust. Regional Assets to support as and when required.	Asset Management Open Spaces
Tūtira Forest Harvest	19. The next tranche of logging is scheduled to begin at Tūtira Regional Park in late January2022. Log prices have risen from lows in November and December 2021 and are forecast to keep rising over the coming months with decreases in shipping costs and increased demand in China. The falcon chicks have left the nest and road construction will continue also.	Asset Management Open Spaces, Forestry
Hawea Historical Park / Karamu Stream Diversion	20. The draft Hawea Historical Park Management Plan is under review with the Management Committee for the Park, Te Ahi kaa roa. The cultural component of the Management Plan was completed in December 2021. 21. Stage 3 project delivery includes pathways around the park, construction work for widening of the confluence, armouring of the eroding embankment and shaping of the stream from the Koru Wetland. Detailed design of the suspension bridge over the Karamu Stream is underway. 22. Design of the Cultural Elements for the Park is underway including costings for DIA funding application in February 2022 - submission in March 2022 and construction in late 2022. The funding application will be completed by the Hawea Historical Park Management Committee. The Regional Asset group will support as required.	Asset Management Open Spaces, Regional Assets
Bayview/ Whirinaki Cycleway	23. NCC confirmed their commitment; however, they advise they will need to delay land negotiations until they have resource available to do this work.	Asset Management Regional Projects
COVID fast-track consenting – ‘Riverbend Residential Development’	24. Environment Minister approved developers’ request to use streamlined consenting process under the COVID-19 Recovery (fast-track consenting) Referred Projects Order 2020 for the Riverbend residential development. 25. Applicants are required to prepare detailed application and assessment of options and effects, including those relating to variety of HBRC interests (e.g. natural hazards, land transport, productive land, strategic urban growth, stormwater infrastructure etc). 26. Consent process is being administered by the Environmental Protection Authority (EPA). HBRC will be involved as a party/submitter – not the decision-maker. 27. There has been no further engagement with the Regional Council on this project.	Policy & Regulation Consents, Schemes, Policy & Planning, HBCDEM, etc.
Tūtira Freshwater Improvement Fund Project	28. Following completion of detailed engineering design to remediate the bed/bank erosion of the lower Kahikanui Stream, work will be undertaken by HBRC Works Groups - scheduled to begin on 24 January 2022. 29. Draft detailed design of the proposed Guthrie Smith wetland development have been completed and an archaeological survey for the site is now being completed ahead of applying for resource consent. 30. The lake is still deemed suitable for swimming. This will be the first Christmas period that the Council will apply the new adaptive risk framework based on multiple monitoring indicators. These include real-time data from the buoy (fast results from all lake depths, but less confidence for any particular reading) with weekly hand-held sensor readings as part of the bathing beaches run (from multiple swimming points on lake). Routine monthly laboratory analysis continue (slower results, most confidence). Results will be constantly reviewed and interpreted cautiously. If a heightened algal bloom risk is detected, an advisory against swimming may be needed – at a time when lake use may be high.	ICM – Catchment Delivery
3D Aquifer Mapping (SkyTEM)	31. Processing and modelling for the Ruataniwha Plains is progressing. 32. Reports drafted and in review for the SkyTEM exploratory drilling on the Ruataniwha plains. 33. Video media being created for the drilling project related to SkyTEM progressing. 34. Release 1 of StoryMap draft completed and awaiting final review from Comms – to be released in February 2022. 35. Online portal development for exploring SkyTEM results finalised and incorporated into StoryMap.	ICM – Environmental Science
3D Aquifer Mapping (SkyTEM)	36. Report finalised for SkyTEM exploratory drilling on the Heretaunga plains – well 17137, Morley Road, Heretaunga Plains. 37. Report finalised for the Heretaunga plains data processing and resistivity models. 38. Report finalised for the interpretation of the Poukawa and Otane Basin resistivity models. 39. Online Portal development for exploring SkyTEM results finalised and incorporated into StoryMap. 40. Report drafted and in review for Heretaunga plains data and model inventory related to SkyTEM. 41. Processing and modelling resistivity for the Ruataniwha plains is progressing. 42. Video media being created for the drilling project related to SkyTEM progressing. 43. Release 1 of StoryMap draft completed and awaiting final review from Comms – to be released in February 2022.	ICM – Environmental Science
Haumoana Ponds	44. A memo on investigation into the source of odour and water quality problems in the Haumoana ponds will soon be circulated to active members of the community. The investigation concludes the problems may be related to discharges from septic tanks. While there is no evidence of direct sewerage contamination or immediate public health risk, nutrients and contaminants from septic systems may be making their way into the ponds and fuelling gross eutrophication, generating decaying organic matter and creating odours. Science have concluded all of the planned investigations, and compliance will be following up with the community in due course.	ICM- Environmental Science

Southern Catchments
Project /Activity Description	Significant Upcoming Milestone(s)	Group /Team or Section
Upper Tukituki Flood Control Scheme	45. Two preferred tenderers have been contacted to undertake tranche 1 of extraction on Tukipo and Makaretu rivers, 116,000m³. Contract awarding is due early February 2022 pending tender confirmation. 46. Request for Tender on Tranche 2 due to be draftedin late February 2022.	Asset Management Regional Projects, Schemes
Lake Whatumā Protection and Enhancement Project	47. A project plan has been established to support the Whatumā Management Group through a programme of subsidised works targeting willow removal, pest plant and animal control, and native planting with works to begin this summer.	ICM – Catchment Delivery
Te Ikatiere Management Plan	48. A contractor has been engaged to complete a management plan for HBRC’s coastal property at Aramoana ‘Te Ikatiere’. This is currently forecast to be complete in February 2022.	ICM – Catchment Delivery

Whole of Region
Project /Activity Description	Significant Upcoming Milestone(s)	Group /Team or Section
Outstanding Waterbodies Proposed Plan Change 7	49. A hui was held on the 24 November 2021 with representatives of the Māori Trustees for Poukawa Moana to enable them to present evidence to staff in support of their appeal. 50. Further mediation will take place in February 2022. 51. A further report date of the 14 March 2022 has been granted by the Court to enable further mediation to occur.	Policy & Regulation Policy & Planning
Presentations at FLRC Conference	52. The Farmed Landscapes Research Centre Conference (FLRC) is being held in Palmerston North form 9-11 February 2022. 53. HBRC presentations will cover: * Our approach to building communities of action in catchments (working with catchment groups). * Development of a risk matrix approach to indicate potential for nitrogen loss in different properties in the absence of Overseer.	Catchments Policy Implementation and Regulatory Policy Implementation
Hill Country Erosion (HCE) Fund	HCE Key activities February: 54. Finalising nursery development milestones to HCE contract. 55. Review of HCE budget with MPI inclusive of variations. 56. Employment and Induction of new nursery assistant. 57. Review and employment of the former HCE workshop co-ordinator. Key Milestones 58. Finalise budget for additional HCE funded re-development work. 59. Confirmation of HCEP next round of funding and application open/close dates. 60. Finalisation of the nursery work plan and deadlines for 2022/23 with Works group. Events: 61. NIWA riparian management course – 23, 24 Feb 2022.	ICM – Catchment Delivery
LiDAR tools project	62. The contract for LiDAR products was expected to be finalised by December 2021, but has been delayed due to resignation of the HBRC project leader. This may delay project commencement by a couple of weeks, which is considered acceptable for this two-year project. 63. Having completed LiDAR data collection for the region, we are working in partnership with Manaaki Whenua Landcare Research to produce new tools to make best use of this data.	ICM – Environmental Science
Radio upgrade	64. Radio purchasing and testing to install new radio system to collect data.	ICM – Environmental Information
Low flows	65. New radars being installed to give us better knowledge at low flow river sites.	ICM – Environmental Information
Lysimeters	66. Four Lysimeters sites being decommissioned and removed	ICM – Environmental Information
Right Tree Right Place	67. With the The Nature Conservancy (TNC) project manager now appointed, detailed project plans have been completed identifying tasks, timelines, resourcing, and responsibilities. This has enabled an update of the Procurement Plan and farm, forestry and other consultancies will now be selected. 68. Relationships are being formalised with several likely pilot farms in Central Hawke’s Bay (CHB). Farm/forestry plans have been completed on one farm with two others about to start this work. The Catchment Delivery team will help identify properties in northern Hawke’s Bay. 69. Seedling lead times are in the order of several years. However, small quantities are in the process of being secured for initial planting starting in 2022. Further work is required to identify options to improve supply chains, which will be discussed with Council over the coming months. 70. Recent media coverage is being well received with Farmers Weekly and National Business Review (NBR) articles following the announcement of the TNC partnership. Engagement with landowners will increase in Feb/Mar 2022, spearheaded by a survey of landowners and supported by direct follow up by the Catchment Delivery Team.	ICM – Catchment Delivery

PMO: Strategic Projects & Key BAU Programme Reporting

Eighteen key strategic (or change) projects/ BAU programmes will now be tracked by the Project Management Office (PMO) and shared monthly throughout the lifecycle of these projects. These projects have been selected because of their significance in terms of investment, risks, benefits, and interdependencies.

*Risk is inherent vs residual risk (i.e., RAG status prior to mitigations and controls implemented).

Performance Indicators: Green = On Track, Amber = At Risk, Red = Off Track, Grey = Not started/On hold

Status Change Keys:

	Project/Programme Title	Schedule	Risks*	Budget	Comment	Status Change
1	Right Tree Right Place Pilot				With detailed project planning work alongside TNC complete, procurement of farm/forestry consultancies is now a priority. Farm selection criteria updated to include Regen Ag aspects and signed off at project Steering GRP meeting in mid-Dec. Detailed farm planning work and farmer engagement to be undertaken from March, which will inform the business case into potential scaled up investment in the project. Progressing Memorandum of Understanding (MoU) with initial pilot farm requires legal/commercial input. Initiating farm/ forestry assessments on other farms. Seedling shortages and other supply chain challenges to be investigated. Work with Catchment Delivery Team (CDT) to identify pilot farms in Northern Hawke’s Bay during Feb/Mar 2022. Need to resolve resourcing for science and environmental monitoring. Meetings with MPI and other ministries re partnership being set up.	Updated since 6 Dec
2	Regional Water Security Programme: Project 1: Heretaunga Water Storage				Primary strategic focus for H2 (half year) 2021-2022 is development of a full feasibility strategy and procurement plan for Council and PDU approval upper-catchment. Advanced pre-feasibility GeoTech investigations completed, and independent peer review first draft received and discussed with providers on 11 Jan 2022. Ecological Assessments underway. Mangaroa Marae walkover took place on 12 Jan 2022. Korongota Marae engagement strategy underway.	Updated since 6 Dec
	Project 2: Managed Aquifer Recharge				Technical workstreams for consenting completed. Mana whenua engagement for Cultural Impact Assessment, and subsequent site visits took place on Nov/Dec. Preferred site potentially impacted by location of new infrastructure by landowner (a risk we were proactively managing). Alternatives available. RWSS 2.0 soft launched in Dec, which will create significant risks and opportunities for MAR consenting.	Updated since 6 Dec
	Project 3: Regional Water Assessment				The Regional Water Assessment Interim Report (draft) shared with Councillors and Executive at 24 Dec 2021. Workshop. A very rough first cut of Water Asset Accounts received on 23 Dec 2021. Meetings with key water management staff at CHBDC, HDC and NCC scheduled for January 2022.	Updated since 6 Dec
3	Ahuriri Regional Park				New dedicated project manager to be appointed by NCC. Project scope needs to be fully defined with NCC. Focus for the next year is to clarify vision, scope, and reconnect with Mana Ahuriri. Three Waters Reform may impact. Proposal to pull budget forward from yr 3 of LTP in order to plan and execute preliminary work under consideration as part of the Annual Plan.	No change since 24 Nov 2021
4	Clifton to Tangoio Coastal Hazards Strategy Implementation				In principle decision for HBRC to take a leadership role in the implementation of the strategy made subject to conditions. Internal review scoped. Draft Memorandum of Transition (MoT) awaiting Joint Committee and Council’s approval. S16 consultation scheduled for May 2022.	No change since 24 Nov 2021
5	On-demand Public Transport				Progress on the project is on track. Buses are likely to be ready by May 2022 for an early June start date. Strategies are being developed to keep public transport access available for bus users with no direct access to the app or a phone by running a fixed off peak route using an on demand bus. Branding and comms/engagement plan are close to completion. Risk and schedule remain amber due to uncertainty over restrictions of movement with COVID (in line with HBRC risk reporting and Omicron). Budget has changed from green to amber due to the fixed school route needing to be operational from start of Term 2 rather than at start of trial.	Updated since 6 Dec
6	Kotahi Plan				Following the Governors Strategic Workshop on the 1 Dec 2021 a further rescheduled hui will be held on 18 Jan 2022 between the tangata whenua reps of the RPC and the Māori Committee to further discuss and agree how they might support this work.	Updated since 6 Dec
6	Kotahi: Mohaka Plan Change				Ngāti Pahauwera and consultants continue to work on the Māori-led workstream and agreed outputs. A further hui is planned for late January with the leaders rōpū to provide feedback and approve the pou work and some of the early TMOTW, values and long-term vision drafting. Once this has been through the rōpū approval process this will be shared more widely with HBRC staff and the RPC. Despite COVID disruptions this is running close to schedule.	Updated since 6 Dec
7	Tukituki Plan Policy Implementation				The first Tukituki production land use consents have now been issued. Still some capacity issues with providers.	Updated since 6 Dec
7	Farm Environmental Management Plans (FEMPs)				FEMP resubmissions were due on 31 May 2021. To date, just over 50% of FEMP resubmissions have been received. 34 properties are being followed up by compliance team. For all other properties yet to resubmit a FEMP, the providers or property owners will be contacted in January 2022. Provider capacity, consent prioritisation and the review of Overseer have caused delays. With only 50% of FEMPs received, schedule and risk moved to red from orange.	Updated since 6 Dec
8	Financial Upgrade Systems and Efficiencies (FUSE)				Jessica Ellerm has now transitioned into the Acting CFO role and will be playing a more active role in aiding the finance team through the adoption of the technology and resolving technical and configuration issues and challenges that the team are facing. Intention to update the C&S committee in Q1 2022. We are seeing some real successes primarily in the enterprise budgeting module which has performed extremely well in preparing the FY2022-2023 Annual Plan budget model. This is a complete business transformation project, not strictly a finance system implementation and process maturity and review will continue to require time and effort right across the organisation for some time.	No change since 24 Nov 2021
9	Te Karamu Catchment Plan			N/A	This role is currently in the recruitment process. Currently behind schedule to fill this position and commence development of plan.	Updated since 6 Dec
10	Ahuriri Catchment Plan			N/A	This role is currently in the recruitment process. Currently behind schedule to fill this position and commence development of plan.	Updated since 6 Dec
11	TANK Plan Change				Budget currently sitting at $4.5m spent to date. Unclear yet whether further caucusing is required following the Hearing held 27 September 2021 with Ngāti Kahungunu Iwi Inc (NKII) and Te Taiwhenua o Heretaunga (TToH). A draft decision is anticipated in late December 2021/January 2022.	Updated since 6 Dec
11	Tank Plan Implementation				Communications plan and pilot materials to be developed and tested, in consultation with the Kotahi programme.	No change since 24 Nov 2021
12	Erosion Control Scheme (ECS) Programme (incl. Soil Conservation Nursery & HCEF)				Capacity and capability, due to shortage in labour market and increasing demand, quality of targeted plants available and rising material costs e.g., fencing materials. Staff working hard to allocate last of the 2021-2022 budget, only fencing projects available given the time of year and time left – fencer availability is problematic.	No change since 6 Dec 2021
13	Water Efficiency Programme Review (Future Water Use)				Dan Bloomer contracted to undertake scoping work and interviews with significant water users in conjunction with Regional Water Assessment engagements. Territorial Authorities (TAs), industry workshop is being held on 15 Feb 2022.	Updated since 6 Dec 2021
14	Ecosystem Prioritisation: Terrestrial				There has been a slight delay in getting the fencing underway due to procurement processes. All sites should still be completed this financial year.	No change since 24 Nov 2021
15	Partial Pest Plan Review				Biosecurity working party established and first workshop held. Independent expert being identified. External stakeholder engagement initiated, with stakeholders booked into discussions over next six weeks. Proposal in progress and currently undergoing edits from an external provider. Establishing communications strategy for community engagement, mediums such as radio and video identified as preferable.	Updated since 6 Dec 2021
16	Flood Control & Drainage Scheme – IRG: Heretaunga Flood Control & Drainage Scheme Levels of Service				Risks being managed are resource availability (consultants and contractors), COVID-19 programme delays and archaeological findings that may cause delay. Physical works have commenced and are ongoing at Taradale. All investigation complete for Moteo, East Clive, Ngatarawa and Roys Hill are complete. Construction for these sites is due to commence in Oct 2022.	Updated since 6 Dec 2021
	Flood Control & Drainage Scheme – IRG: Upper Tukituki Flood Control Scheme				Risks being managed are market engagement, achieving targeted extraction volumes within allocated budget and funding timeframe, COVID-19 programme delays. First round tender has four submissions, demonstrating active market engagement. Tender assessment planned for week of 17 January 2022, with negotiation and first contracts awarded thereafter.	Updated since 6 Dec 2021
	Flood Control & Drainage Scheme – IRG: Wairoa River, River Parade Erosion				Risks being managed are COVID-19 programme delays (Covid worksite protocols) for working in the new Covid traffic light system Wairoa currently a RED ZONE, Temporary Traffic management in place awaiting guardrail to be installed (24-28 Jan 2022). Planting scheduled for autumn.	Updated since 6 Dec 2021
17	Revenue & Financing Policy/ Rates Review (incl. Scheme Rating Reviews)				This project has not started, and will commence upon the appointment of new CFO.
18	Enterprise Asset Management				This project is due to commence in Feb 2022.

Project Summaries

1	Right Tree Right Place Pilot on up to five farms to understand the detail set-up costs, partnership, and delivery options. Under the trial, we would offer a loan to landowners to plant trees on their erodible land. Opportunities being explored with The Nature Conservancy.
2	Regional Water Security Programme PGF funding has allowed us to investigate water supply options through two projects: Heretaunga Water Storage and Managed Aquifer Recharge in Central Hawke’s Bay. A 50-year Regional Water Assessment will inform the work, including regional water supply and demand into a future challenged by climate change.
3	Ahuriri Regional Park Working alongside NCC to redevelop the Lagoon Farm site into a Regional Park will allow for stormwater detention and wetland treatment for improved environmental outcomes, as well as providing cultural, educational, and recreational opportunities.
4	Clifton to Tangoio Coastal Hazards Strategy Implementation Working with HDC and NCC to implement the long-term (100 year) adaptive strategy for responding to coastal erosion and coastal inundation in priority areas of the coast between Clifton and Tangoio.
5	On-Demand Public Transport A new form of public transport that replaces fixed routes with an on-demand service. This will be a trial in Hastings which uses innovation and technology to lower the region’s transport emissions, provide better transport choices for the community and will give more equitable access to public transport.
6	Kotahi Is a combined resource management plan for the Hawkes Bay region. The Regional Policy Statement and Regional Plan combined, and the Regional Coastal Environment Plan are due for review. In addition, the NPSFM 2020 requires us to develop a plan to give effect to Te Mana o Te Wai.
7	Tukituki Plan Policy Implementation Implementation of statutory deliverables related to the Tukituki Plan, with particular focus on changes arising from the Government’s response to the Science Advisory Panel’s review of Overseer. Farm Environmental Management Plans (FEMPs) FEMPs aim to address environmental outcomes and actions to improve environmental performance on properties over 4ha within the Tukituki region at this stage 3 yearly submission cycle – first resubmission was due 31 May 2021.
8	Financial Upgrade Systems and Efficiencies (FUSE) The implementation of the new financial system TechOne. FUSE will standardise processes, and improve transparency and accessibility of financial data, and financial process efficiencies.
9	Te Karamu Catchment Plan The new plan will collate intelligence on all parties and their activities in the Karamu Catchment. This will be utilised to provide visibility on activities within the catchment and identify options to influence for improved water quality and biodiversity outcomes.
10	Ahuriri Catchment Plan The new plan will collate intelligence on all parties and their activities in the Ahuriri catchment. This will be utilised to provide visibility on activities within the catchment and identify options to influence for improved water quality and biodiversity outcomes.
11	TANK Plan Change (Policy) Proposed TANK Plan Change (PPC9) will add new rules to the Regional Resource Management Plan to manage water quality and quantity for the Tūtaekurī, Ahuriri, Ngaruroro and Karamū (TANK) catchments. TANK Plan Change (Implementation): TANK Subcatchments Community Engagement An external comms project, intended to inform rural landowners about the PC9 framework and to promote catchment group formation. It is a precursor to the overall PC9 Implementation, the latter contingent on a decision awaited from Hearings Commissioners and any subsequent appeals.
12	The Erosion Control Scheme (ECS) Provides access to a grant for Hawke's Bay landholders to implement soil conservation measures on highly erodible land, keeping soil on the hills and out of waterways. It provides significant financial support for erosion control work such as non-commercial tree planting, protection fencing, land retirement and assisted reversion. Hill Country Erosion Fund (HCEF) Is Central Government funding to support ECS activities and events that are targeted at educating and supporting staff and landowners with the reduction of hill country erosion. Soil Conservation Nursery The primary purpose of the nursery is to grow poplar and willow poles for erosion control and are managed primarily for the ECS and Works Group, river control plantings.
13	Future Water Use ‘Future Water Use’ – making better use or the water we have to complement water storage. Work with water users to drive more efficient and effective use to complement water storage.
14	Ecosystem Prioritisation: Terrestrial This programme focuses on protecting and enhancing 700 Ecosystem Prioritisation sites across the region. To achieve this, we have partnered with internal and external stakeholders alongside land occupiers. The main actions are deer fencing, pest plant and animal control and some enhancement planting. Ecosystem Prioritisation: Coastal and Marine The Coastal and Marine team have undertaken scientific investigations to identify biodiversity prioritisation sites off the coast of Mahia and Clive, using Zonation software to inform spatial management. The outcomes and recommendations have been concluded and can now move forward to implementation phase.
15	Partial Pest Plan Review Investigating changing the current Possum Control Area Programme from an occupier responsibility model to a large-scale contract model. A contracting model will secure the continued success long term of the outcomes delivered by low possum numbers and increase the biodiversity benefits from consistently low possum numbers.

Enforcement Actions
70. There are 13 active prosecutions before the court, at various stages therefore not able to comment publicly on. There are 3 further investigations in progress likely to lead to prosecution.
Date	Type of Enforcement Action	Status
Sep 2021	Burning prohibited items	Before the court
Jun 2021	Discharge to land/water	Before the court
Apr 2021	Contravention enforcement order	Before the court
Feb 2021	Discharge to land that may enter water	Before the court – Plea to enter
Jan 2021	Discharge to air - odour	Before the court – Plea to enter
Nov 2020	Burning prohibited items	Before the court – NG
Nov 2020	Discharge to land that may enter water	Before the court – NG
Jul 2020	Discharge to land that may enter water	Before the court – NG
Jun 2020	Burning prohibited items	Before the court – awaiting Sentencing
Jun 2020	Discharge to land that may enter water	Before the court – NG
Jun 2020	Discharge to land that may enter water	Before the court – NG
Mar 2020	Discharge to land that may enter water	Before the court – NG
Jun 2019	Burning prohibited items	Before the court – awaiting sentencing

Environment Court Processes
Date	Type of Enforcement Action	Status
January 2022	Outstanding Water Bodies Plan Change (PC7) (three appeals on Independent Panel’s decisions made on behalf of the Regional Council).	Preliminary mediation session held on 27 October 2021. Further mediation is due to commence the week of 21 February 2022.
	Appeals to the Draft Water Conservation Order application for Ngaruroro River	Before the court.

Decision Making Process

2. Staff have assessed the requirements of the Local Government Act 2002 in relation to this item and have concluded that, as this report is for information only, the decision-making provisions do not apply.

Recommendation

That Hawke’s Bay Regional Council receives and notes the “Significant organisational activities looking forward through February 2022” staff report.

Authored by:

Janine Barber

Principal Scientist Groundwater Quality

Michael Bassett-Foss

RTRP Project Manager

Allan Beer

Team Leader Biosecurity - Animal Pests

Sarah Bell

Team Leader Strategy & Performance

Jack Blunden

Team Leader Compliance - Urban & Industrial

Vicki Butterworth

Cycle Network Coordinator

Desiree Cull

Strategy & Governance Manager

Peter Davis

Manager Environmental Information

Ben Douglas

Forest Management Advisor

Ceri Edmonds

Manager Policy and Planning

Russell Engelke

Team Leader Open Spaces

Craig Goodier

Principal Engineer

Martina Groves

Manager Regional Assets

Simon Harper

Senior Scientist

Nathan Heath

Area Manager Northern Hawke's Bay

Dr Andy Hicks

Team Leader/Principal Scientist Water Quality and Ecology

Rob Hogan

Manager Compliance

David Keracher

Manager Regional Projects

Campbell Leckie

Manager Catchment Services

Anna Madarasz-Smith

Team Leader Marine, Air and Land Science

Julie-Anne McPhee

Senior Project Manager

Malcolm Miller

Manager Consents

Mark Mitchell

Team Leader Principal Advisor Biosecurity Biodiversity

Thomas Petrie

Programme Manager Protection & Enhancement Projects

Brendan Powell

Manager Catchments Policy Implementation

Dr Jeff Smith

Manager Science

Jolene Townshend

Senior Advisor Integrated Catchment Management

Mell Anderson

Project Manager Hill Country Erosion Scheme

Approved by:

Katrina Brunton

Group Manager Policy & Regulation

Chris Dolley

Group Manager Asset Management

Iain Maxwell

Group Manager Integrated Catchment Management

Attachment/s

There are no attachments for this report.

Topic	Raised by

Topic	Raised by